Effective Date: June 2026
Welcome to Studio Manishi. By accessing our website, submitting inquiries, engaging our services, or communicating with us through any digital platform, you agree to the following Terms & Conditions.
Studio Manishi is an architecture and interior design studio based in Ahmedabad, Gujarat, offering services including but not limited to:
Residential Architecture
Interior Design
Luxury Interior Design
Turnkey Interior Projects
Villa Design
Commercial Interior Design
Vastu Consultation
3D Architectural Visualization
3D Interior Visualization
Renovation & Remodeling
Land Plotting Planning & CAD Documentation
Design Consultancy Services
The information provided on this website is intended for general informational purposes only.
While Studio Manishi strives to maintain accurate and up-to-date information, we do not warrant the completeness, reliability, or accuracy of any content displayed on the website.
All designs, concepts, images, renderings, specifications, and project representations are subject to revision and project-specific requirements.
Submission of an inquiry through our website, phone, WhatsApp, email, or any digital platform does not constitute a formal appointment or contract.
A professional relationship shall commence only after:
Scope of work is defined
Commercial terms are agreed upon
Necessary documentation is executed
Advance payment, if applicable, is received
All design services are customized based on project requirements.
Deliverables may vary depending on:
Project type
Scope of services
Site conditions
Client requirements
Budget considerations
Regulatory requirements
Studio Manishi reserves the right to modify design recommendations when necessary to address technical, practical, statutory, or safety concerns.
Clients are responsible for providing:
Accurate site information
Property documents
Existing drawings (if available)
Project requirements
Budget expectations
Timely approvals and feedback
Delays caused by incomplete information or delayed approvals may affect project timelines.
Professional fees, consultation charges, design fees, visualization charges, and turnkey project costs shall be communicated separately through quotations, proposals, or agreements.
Unless otherwise agreed:
Advance payments are non-refundable once work has commenced.
Outstanding payments may result in suspension of services.
Deliverables may be withheld until payment obligations are fulfilled.
Studio Manishi may recommend consultants, vendors, contractors, suppliers, or service providers.
However:
Studio Manishi is not responsible for independent actions, workmanship, delays, pricing, warranties, or contractual obligations of third-party service providers.
Clients are encouraged to independently verify credentials and commercial terms before engagement.
For turnkey execution projects:
Project schedules are dependent upon site readiness, material availability, labor availability, approvals, weather conditions, and unforeseen circumstances.
Estimated timelines are indicative and may vary during execution.
Material availability and market fluctuations may impact project costs.
All renderings, walkthroughs, and visualizations are artistic representations intended for design communication purposes.
Actual construction outcomes may vary due to:
Material selections
Lighting conditions
Site execution
Vendor capabilities
Product availability
Vastu recommendations are provided as guidance based on traditional principles and professional interpretation.
Studio Manishi does not guarantee specific personal, financial, commercial, spiritual, or business outcomes arising from implementation of Vastu recommendations.
All content available on this website, including but not limited to:
Designs
Drawings
Layouts
Visualizations
Photographs
Graphics
Logos
Brand assets
Text content
remain the exclusive intellectual property of Studio Manishi unless otherwise stated.
No content may be copied, reproduced, modified, distributed, published, or used without prior written permission.
Unless restricted through a written agreement, Studio Manishi reserves the right to:
Photograph completed projects
Document project progress
Publish project images
Use project information for portfolio, marketing, social media, awards, publications, and promotional purposes
Confidential client information will not be disclosed without consent.
To the maximum extent permitted by law, Studio Manishi shall not be liable for:
Indirect damages
Consequential damages
Business losses
Loss of profits
Delays caused by external factors
Actions of third-party consultants or contractors
Regulatory approval delays
Our liability shall be limited to the professional fees received for the specific service engaged.
Users agree not to:
Misuse website content
Attempt unauthorized access
Introduce malicious software
Copy or distribute copyrighted material
Use the website for unlawful purposes
Violation may result in legal action.
This website may contain links to third-party websites.
Studio Manishi is not responsible for:
Content accuracy
Privacy practices
Availability of third-party websites
Services offered by third parties
Studio Manishi reserves the right to modify these Terms & Conditions at any time without prior notice.
Updated versions will become effective immediately upon publication on the website.
These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.
Any disputes arising from these terms shall be subject to the exclusive jurisdiction of the courts of Ahmedabad, Gujarat.
Studio Manishi
B-304, Sanskrit Galleria
Memnagar Subhash Chowk
Gurukul Road
Ahmedabad, Gujarat, India
Email: info@studiomanishi.com
Phone: +91 9270339239
By accessing this website or engaging our services, you acknowledge that you have read, understood, and agreed to these Terms & Conditions.
Select Date Select time
30 min Meeting
08:00 AM - 08:30 AM, Thursday, Nov 24, 2024
Indian Standard Time
Shahanab
